|
Wyoming Lawyer Search - Listings for Mattimoe Patrick C Attorney at Law
Name: Mattimoe Patrick C Attorney at Law
Address: 154 W Lake Rd Pinedale, WY 82941
Phone Number: 307-367-2404
|
Specialties:
|
Bankruptcy Law
|
|
|
|
Cases related to this attorney's specialties:
COPELAND v. VENEMAN United States Court of Appeals for the Federal Circuit 03-1326 1000 BILL J. COPELAND, Appellant, v. Ann M. Veneman, SECRETARY OF AGRICULTURE, Appellee. Bill J. Copeland, of Banning,California, pro se. Michael N. O'Connell, Trial Attorney, Commercial Litigation Branch, Civil Division, United States Department of Justice, of Washington, DC, for appellee. With him on the brief were Peter D. Keisler, Assistant Attorney General; David M. Cohen, Director; and Harold D. Lester, Jr., Assistant Director. Appealed from: Department of Agriculture Board of Contract Appeals United States Court of Appeals for the Federal Circuit 03-1326 BILL J. COPELAND, Appellant, v. Ann M. Veneman, SECRETARY OF AGRICULTURE, Appellee. _ DECIDED: November 26, 2003 _ Before LOURIE, BRYSON, and DYK, Circuit Judges. DYK, Circuit Judge. This is an appeal from a Board of Contract Appeals decision denying appeals of default terminations on two contracts and denying other numerous discrete claims. BACKGROUND In September 1991, the appellant was awarded two construction contracts by the National Forest Service to construct and reconstruct trails in the San Bernadino National Forest. Contract No. 50-9JA9-1-1L039 ("the Trail Contract") was awarded in the amount of $112,900 with a completion date of May 21, 1992, and Contract No. 50-9JA9-1-1L026 ("the Comfort Station Contract") was awarded in the amount of $147,777 with a completion date of June 20, 1992. The appellant was to be paid a series of progress payments. These contracts incorporated provisions of the Davis Bacon Act ("DBA"), Pub. L. No. 107-217, 2002 U.S.C.C.A.N. (116 Stat.) 1062, 1150-1153 (2002), which sets wage and payment guidelines for contractors engaged in public works contracts with the federal government in excess of $2,000. During performance of these contracts in March of 1992, various employees complained of DBA wage violations on the Trail Contract. The Forest Serv...
|
|
|